Signature and Above WarrAnty

My Cabinet Factory, Inc. One Year Limited Warranty

My Cabinet Factory, Inc. (MCF) warrants its cabinetry products by providing to the original consumer purchaser a limited warranty for a period of one year from the original date of purchase. Should any of our products fail due to defects in material or workmanship under normal use within this one year period, MCF will, at its discretion, repair or replace the defective part. 

This warranty does not cover products that are misused, abused, mishandled, improperly stored, improperly installed, changed, modified, or subjected to extreme temperatures or moisture levels, or normal wear and tear. This warranty is not valid for products used for any purpose other than the purpose for which they were originally intended. Variations in color and grain pattern are a natural characteristic of wood. Color changes may also occur because of exposure to light and other elements, including, but not limited to, household cleaners, heat, smoke and other environmental conditions. These variations and changes are not covered by this warranty. 

In addition, all Blum hinges and slides used in the manufacture of MCF are covered by a limited lifetime warranty by the manufacturer of the hinges and slides. This warranty is passed to the original consumer purchaser by MCF and is subject to the conditions as outlined in paragraph two above.

Terms and Conditions:

TERMS AND CONDITIONS My Cabinet Factory Inc.- 3464 Hwy 411 NE White, GA 30184 -770.382.8442, (fax) 770.382.8425Terms and conditions as stated herein become a part of our quotation and will apply to the acceptance by My Cabinet Factory Inc. (herby referred to as My Cabinet Factory) of your order. All terms and conditions expressly specified herein shall render null and void any conflicting terms and conditions in any and all other contracts relative to this proposal.1) Quoted prices are valid for 30 days. Project scheduling will begin upon receipt of 50% fabrication deposit. No work will be scheduled prior to receipt of 50% deposit for any reason.2) Prices include GA sales tax. GA state sales tax will be applied to all projects unless other arrangements have been made.3) Design deposits or fees will include one 2D black and white line drawing or one 3D color rendering as specified on the proposal. The design deposit or fee will include one review and revise session with one re-submittal of drawings or renderings. Additional changes to the design or concept will be billed at $100 per hour. Design deposits do not include shop drawings unless otherwise stated; shop-drawing costs are included in the production budget. Shop drawings will not be produced until: 1) the design concept rendering has been approved and 2) the 50% production deposit has been received. Design deposits will be applied toward the 50% production deposit. All jobs include a design fee unless detailed drawings and specifications have been supplied prior to price quoting.4) Shop drawings will include the following: Elevations, cross sections and plans that will identify all critical dimensions, chosen appliances/electronic components not to be supplied by My Cabinet Factory, hardware and special features. If it is not shown or addressed on the drawings or submittals provided, then My Cabinet Factory has not agreed to supply it. All shop drawings and product samples must be signed, dated and returned before My Cabinet Factory will proceed with the manufacture of any project. Any detail pertaining to cabinet construction and installation that is not specifically discussed and documented will be performed at the discretion of My Cabinet Factory. The shop drawings will include one review and revise session with one re-submittal of drawings. Additional changes to the shop drawings will be billed at $65 per hour.5) My Cabinet Factory's finishes are among the most consistent available. Our multiple step technique combined with the careful selection of color matched woods and veneers ensure that the finished project will be as consistent as possible. However, since the properties of wood are not consistent themselves, we cannot ensure that each part of the project will look exactly alike, nor can we guarantee that the project will exactly match the initial sample. Therefore, My Cabinet Factory does allow for a range of color on its finished products. This acceptable color range may sometimes span several shades above or below the average shade for a stain/specie combination. Variations may also occur in hand applied paint finishes such as pickled, ragged, glazed, crackle, etc., these variations are normal. Each project is entitled to one custom-made finish board, additional boards will be created on a time plus material basis with a $100 minimum charge. All finish samples must be signed, dated and returned before My Cabinet Factory will proceed with the finishing stage of any project.6) Correction of Work: After the contract is substantially completed, a representative from My Cabinet Factory and the customer/customer's representative shall jointly inspect the work and a single list (punch list) shall be prepared identifying allwork to be completed or corrected. There shall be only one such written list of work identified to be incomplete or incorrect, and the customer/customer's representative shall sign the list. My Cabinet Factory shall then expeditiously complete all work stated on the punch list for which they are responsible in the terms of this Agreement. The customer/customer's representative shall not contract with any alternative contractor for the performance or completion of work within the scope ofthe Agreement, nor shall the customer/customer's representative claim a credit or back charge for the cost of completing an item stated on the written punch list, nor shall the customer/customer's representative occupy or use the stated work until and unless My Cabinet Factory is first given reasonable notice and opportunity to correct the work stated on the punch list referred to above. If the customer/customer's representative does contract with an alternate contractor to perform the punch list work or otherwise completes the project without first affording the above-described opportunity to My Cabinet Factory, or if the customer/customer's representative commences to use or occupy the space or work in which My Cabinet Factory performed work, the customer then agrees to accept all work "as is" and thereby waives any claim against My Cabinet Factory under the terms of the Agreement, including warranty claims.7) Warranty: It will be the responsibility of My Cabinet Factory to insure that all material, products and taxes relating to the customer's project are paid and that there will be no potential lien claimants after the customer's final payment has been made to My Cabinet Factory. All work shall be performed in a professionally reasonable manner. Materials or hardware used by My Cabinet Factory or its subcontractors shall be warranted only to the extent that the suppliers or manufacturers of those products provide a warranty. In the event that a defect is discovered in one of these products, My Cabinet Factory will assist the customer in securing a replacement or repairing the products for the duration of the product manufacturer's warranty.8) My Cabinet Factory is not responsible for any plumbing, electrical, flooring, painting, decoration or other construction work unless specifically stated in the design specifications and construction details that are part of this agreement. My Cabinet Factory will not be held liable for reasonable damage to paint, wallcovering, floorcovering and ceiling materials associated with the installation of custom millwork.9) Storage and handling charges will be applied to any and all projects undeliverable for more than 30 days due to delays caused by the real property owner, architects, interior designers, contractors, service people, vendors or any other source not including subcontractors, vendors and suppliers hired or paid directly by My Cabinet Factory. Storage charges are assessed at $ .75 per square foot, per day, 7 days a week. Handling charges are assessed at $65 per hour. Charges will apply to all projects at any point during the fabrication process beginning upon delivery of raw materials. Charges will apply until projects are delivered or fabrication has commenced, re- scheduling for delivery or fabrication will be dependent upon My Cabinet Factory's workload at that time. Charges will be invoiced monthly and will be due prior to delivery or installation of any projects. Projects delivered to a site and not installed due to delays by others will be subject to full payment minus the cost of installation as determined by My Cabinet Factory at its sole discretion.10) My Cabinet Factory does not guarantee any shipment or delivery date. Any time or date stated herein or otherwise identified by My Cabinet Factory or any of its agents or employees for shipment or delivery is intended as an estimate only. Accordingly, My Cabinet Factory shall not be liable for any damages of any nature whatsoever arising directly or indirectly out of a delay in shipment or delivery.11Terms are as follows. 50% paid on deposit, 40% upon completion of manufacturing prior to delivery 10% upon completion of installation. Projects with, for any reason, past due balances, partial payments, returned checks, etc. may be delivered and or installed on a pre- paid basis at the sole discretion of My Cabinet Factory.